These Terms & Conditions (“Terms”) govern access to and use of the website and services provided by Joseph Ellen Designs (“we,” “us,” “our,” or the “Company”). By accessing or using the Services, you agree to these Terms.
If you do not agree, do not use the Services.
1. Services Provided
Joseph Ellen Designs provides interior design, consulting, and related creative services. Services may vary by project and are subject to separate written agreements, proposals, or invoices where applicable.
Website content is for informational purposes and does not constitute a contract or design proposal.
2. No Warranty & No Guarantees of Outcome
Design services involve creative judgment and subjective interpretation. We do not guarantee specific outcomes, financial results, rental performance, booking rates, or return on investment.
All implied warranties are disclaimed to the maximum extent permitted by law.
3. Intellectual Property
All website content including text, images, layouts, branding, and design assets are property of Joseph Ellen Designs or its licensors and may not be copied, reproduced, or redistributed without written permission.
Clients may receive usage rights for design deliverables only as outlined in individual agreements.
4. Client Responsibilities
Clients may be required to:
-
Provide accurate project information
-
Secure access to property
-
Provide timely approvals
-
Coordinate contractors or trades unless otherwise agreed
We are not responsible for delays or defects caused by third-party vendors, trades, or suppliers not under our control.
5. Payments & Billing
Unless otherwise agreed in writing, invoices are due upon receipt. Deposits, retainers, or progress payments may apply for certain services. Failure to pay may result in suspension or termination of services.
We are not responsible for bank fees, currency conversion, or financial processing charges.
6. Third-Party Vendors & Contractors
Projects may involve third-party services such as:
-
General contractors
-
Installers
-
Photographers
-
Furniture suppliers
-
Tradespeople
We do not supervise third-party entities unless contractually agreed. We are not liable for their workmanship, delays, defects, pricing, or warranties.
7. Limitation of Liability
To the fullest extent permitted by law, the Company shall not be liable for indirect, incidental, consequential, punitive, or special damages arising from use of the Services.
Liability, if any, shall be limited to the amount paid to the Company for the applicable services.
This clause protects you against excessive litigation exposure.
8. Indemnification
Users and clients agree to indemnify and hold the Company harmless from claims arising from misuse of the Services or breach of these Terms.
9. Website Use
Users agree not to:
-
Reverse engineer the site
-
Copy or reproduce materials
-
Interfere with functionality
-
Attempt unauthorized access
-
Use content for unlawful purposes
10. Governing Law
These Terms are governed by the laws of the State of Florida and applicable U.S. federal law. Venue for disputes shall be in Duval County, Florida.
11. Termination
We may suspend or terminate access to the Services with or without cause.
12. Changes to Terms
We may update these Terms at any time. Continued use constitutes acceptance.
13. Contact Information
Joseph Ellen Designs
1718 Atlantic Blvd
Jacksonville, FL 32207
Email: contact@josephellendesign.com
Phone: (904) 321-9031